(DOWNLOAD) "Chaney Building Co. v. Sunnyside School District No. 12" by Arizona Court of Appeals # eBook PDF Kindle ePub Free
eBook details
- Title: Chaney Building Co. v. Sunnyside School District No. 12
- Author : Arizona Court of Appeals
- Release Date : January 03, 1985
- Genre: Law,Books,Professional & Technical,
- Pages : * pages
- Size : 69 KB
Description
Chaney Building Co., Inc. appeals from a directed verdict in favor of Sunnyside Unified School District No. 12 in a case brought to recover contract payments withheld for performance delay, on the grounds that the terms of the contract required Chaney to give written notice within 7 days from the beginning of any delay and that the lack of evidence of compliance with this provision entitled Sunnyside to judgment as a matter of law. The contract completion date was August 21, 1982. Chaney, after completing the project on or about November 23, 1982, requested a 90-day extension. Sunnyside only granted a 21-day extension, and after determining the project was 73 days late, assessed a penalty of $18,177 as liquidated damages.
 "Chaney Building Co. v. Sunnyside School District No. 12" by Arizona Court of Appeals # eBook PDF Kindle ePub Free){kind=link}